Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question.
Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair.
For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor.
The Civilian Board of Contract Appeals explained that a listing of items or events leading to unforeseeable, excusable delay is NOT intended to give the contractor free rein or a get-of-jail free card if the contractor encounters such delaying item or event:
Nevertheless, the mere fact that a delay is caused by a type of activity listed in the contract as generally excusable does not give the contractor carte blanche to rely upon such excuses. “The purpose of the proviso,” which is “to protect the contractor against the unexpected, and its grammatical sense both militate against holding that the listed events are always to be regarded as unforeseeable, no matter what the attendant circumstances are.” As the Supreme Court has explained, “[a] quarantine, or freight embargo, may have been in effect for many years as a permanent policy of the controlling government” and, if so, may not meet the definition of a cause “unforeseeable” at the time of contract award, even if quarantines and freight embargoes are listed in the contract as examples of possible excusable causes of delay.
Further, even if an unforeseeable cause of delay occurs, the contractor cannot sit back and fail to take reasonable steps in response to it — once such an unforeseeable event occurs, the contractor affected by it has an obligation to attempt to mitigate the resulting damage to the extent that it can. If the contractor fails to do so, it “may not recover those damages which could have been avoided by reasonable precautionary action on its part.”
Yates-Desbuild Joint Venture v. Department of State, CBCA 3350, 2017 WL 4296219 (CBCA 2017) (internal citations omitted).
Now, think about your construction contract. It may list similar items or events constituting delay. Perhaps it expands on this list and identifies COVID, the Russia-Ukraine war, or supply chain impacts. Similar to the reasoning above, “the mere fact that a delay is caused by a type of activity listed in the contract as generally excusable does not give the contractor carte blanche to rely upon such excuses.” Yates-Desbuild Joint Venture, supra. We know of the existence of COVID, the Russia-Ukraine war, and current supply chain impacts such that they are not unforeseeable. And, encountering such an item or event cannot be used to compensate for other delays as the contractor “cannot sit back and fail to take reasonable steps in response to it.” Yates-Desbuild Joint Venture, supra. The contractor still must mitigate the item or event it claims is causing excusable delay.
This serves as an example as to why you want clarity in your construction contract. If you are identifying an item or event as unforeseeable, make sure it truly is or specify the context in which the item or event constitutes excusable delay.
Please contact David Adelstein at firstname.lastname@example.org or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.