WHICH CONSTRUCTION CONTRACT SHOULD I USE?

In the previous article I posted a chart that includes a side-by-side comparison of common risk allocation and risk assumption provisions in industry form construction contracts (the general conditions between the owner and contractor in the AIA, EJCDC, and ConsensusDocs industry form contracts).   This chart was used to illustrate various contractual provisions in industry form contracts in a presentation I recently did on construction contracts. The point of the presentation was to summarize many of the common risk allocation and risk assumption provisions in construction contracts that need to be considered when selecting and finalizing an industry form construction contract.  A portion of that presentation is below.  

 

[gview file=”https://floridaconstru.wpengine.com/wp-content/uploads/2016/10/Advanced-Construction-Contracts.pptx”]

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

IMPACT OF LIS PENDENS ON UNRECORDED INTERESTS / LIENS

Foreclosure-1In a previous article, I discussed the importance of recording a lis pendens in a construction lien foreclosure action.

 

There is another noteworthy point relating to the impact of lis pendens that can provide quite a bit of consternation.

 

Florida Statute 48.23(1)(d) provides:

 

Except for the interest of persons in possession or easements of use, the recording of such notice of lis pendens, provided that during the pendency of the proceeding it has not expired pursuant to subsection (2) or been withdrawn or discharged, constitutes a bar to the enforcement against the property described in the notice of all interests and liens, including, but not limited to, federal tax liens and levies, unrecorded at the time of recording the notice unless the holder of any such unrecorded interest or lien intervenes in such proceedings within 30 days after the recording of the notice. If the holder of any such unrecorded interest or lien does not intervene in the proceedings and if such proceedings are prosecuted to a judicial sale of the property described in the notice, the property shall be forever discharged from all such unrecorded interests and liens. If the notice of lis pendens expires or is withdrawn or discharged, the expiration, withdrawal, or discharge of the notice does not affect the validity of any unrecorded interest or lien.

 

The language in this statute requires persons with unrecorded interests / liens to intervene in a lawsuit subject to a lis pendens within 30 days or else they are barred from proceeding against the property (unless the property subject to the lis pendens is not foreclosed on or the lis pendens is discharged).  This is a harsh outcome because such a person’s (unrecorded) interest may not accrue until it is already too late—beyond the 30 days of the recording of the lis pendens.

 

The best way to explain the potentially harsh application of this statute is to examine its application in a few cases.

 

In Adhin v. First Horizon Home Loans, 44 So.3d 1245 (Fla. 5th DCA 2010), a lender recorded mortgages associated with a construction loan.  The borrower entered into an agreement to sell parcels and any homes currently built on the parcels.  The parcels were sold, however, the closing agent failed to record the deeds and mortgages associated with the closing, and failed to secure any release from the construction lender as to the parcels that had been sold.   Subsequently, the construction lender foreclosed on its mortgage which included a foreclosure that applied to the parcels that had been sold.  A lis pendens had been recorded.   Approximately two months after the lis pendens was recorded, the purchasers of the parcels recorded their deeds and corresponding mortgages and moved to intervene in the construction lender’s foreclosure lawsuit.   The construction lender opposed the motion to intervene arguing that the purchasers of the parcels failed to timely intervene pursuant to s. 48.23(1)(d) since the lender’s foreclosure action impacted their rights to the parcels they purchased.  The appellate court agreed with the lender finding that the language operates as a nonclaim statute that bars enforcement against the property by a holder of an unrecorded interest (such as the purchasers of the parcels in this case) after the prescribed statutory period (30 days), provided the litigation proceeds to a final judgment and judicial sale of the foreclosed property.  This meant the purchasers of the parcels could not intervene and their rights as it related to their parcels were entirely dependent on whether the construction lender’s foreclosure action proceeded to a final foreclosure judgment and judicial sale of the property (inclusive of their property).  Ouch!!!

 

In Jallali v. Knightsbridge Village Homeowners Ass’n, Inc., 2016 WL 3548843 (Fla. 4th DCA 2016), a homeowner’s lender filed a mortgage foreclosure action and recorded a lis pendens.   While the mortgage foreclosure action was pending, the homeowner’s association recorded a lien for unpaid assessments and moved to foreclose its assessment lien.  The issue was whether the lender’s notice of lis pendens barred the homeowner’s association’s subsequent foreclosure action based on its lien for unpaid assessments.   The appellate court held it did not because the lien was based on a recorded Declaration of Covenants that was recorded prior to the filing of the lis pendens—thus, s. 48.23(1)(d) did not apply because the Declaration was an interest recoded prior to the lis pendens.

 

In Ober v. Town of Lauderdale-by-the-Sea, 2016 WL 4468134 (Fla. 4th DCA 2016), a lender filed a foreclosure action and recorded a lis pendens.  The lender obtained a final judgment in foreclosure.  Subsequent to the final judgment in foreclosure, but before any foreclosure sale, the Town of Lauderdale-by-the-Sea recorded liens against the property for code violations that occurred post-final judgment.  The property was sold at a foreclosure sale and the new owner filed suit to quiet title and remove the Town’s liens.  The appellate court held that s. 48.23(1)(d) does not operate to bar liens that accrue and are recorded AFTER the final judgment.  Hence, recording a lis pendens does not operate to bar liens that occur (accrue) and are recorded post-final judgment but before a foreclosure sale.

 

When it comes to construction projects, sometimes there are multiple construction lien foreclosure actions relating to the same property. All of these foreclosure actions are routinely accompanied by a lis pendens.  Some of these actions could arguably be barred under s. 48.23 since they may be based on liens recorded outside of the 30-day window of the first lis pendens that was recorded.  So, if the initial foreclosure action results in a judicial sale of the property, the subsequently recorded liens on the property whose holder’s failed to timely intervene may be out of luck – they would not be able to foreclose on the same property that was already sold at a judicial sale.  On the other hand, under Jallali, liens relate to a notice of commencement, and similar to a Declaration of Covenants (or Condominium), could be considered a recorded interest.  The notice of commencement would be recorded prior to any construction lien, meaning that any construction lien is not based on an unrecorded interest at the time a lis pendens is recorded.  If this is true, than s. 48.23(1)(d) arguably would not apply to bar any liens that accrue and/or are recorded after 30 days from the initial lis pendens.  To preserve this argument, it is important that liens are recorded within the effective period of a notice of commencement so that the liens can relate back to the date the notice of commencement is recorded. 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

MILLER ACT CLAIM FOR UNSIGNED CHANGE ORDERS

imagesContracts and subcontracts often contain language that requires change orders to be in writing and that no change order work shall be performed unless agreed to in advance in a signed change order.  Oftentimes change order work is performed but the parties have not complied with the strict requirements of the contract by having this work signed off by the parties in a change order prior to the commencement of the work.  Well, can such requirements be waived?  If so, can such change orders form the basis of a Miller Act claim?   The answer is generally yes provided the party arguing waiver can support the waiver with evidence (that the other party voluntarily relinquished the requirements through its course of conduct / actions).

 

This is exemplified in U.S. f/u/b/o Agate Steel, Inc. v. Jaynes Corp., Case No. 2:13-CV001907-APG-NJK (D. Nev. June 17, 2016), where a sub-subcontractor asserted a Miller Act payment bond claim for non-payment largely dealing with change order work that was never signed by the subcontractor that hired it.   The subcontract stated:

 

No change orders or contract additions will be made unless agreed to in writing….If additional work is performed and not covered in this contract [sub-subcontractor] proceeds at [its] own risk and expense. No alterations, additions, or small changes can be made in the work or method of the performance, without the written change order signed by [subcontractor] and [sub-subcontractor]. 

Jaynes, supra.

 

The sub-subcontractor submitted change order requests and time and material summaries to the subcontractor that hired it.  However, the subcontractor never signed the change orders or time and material summaries. The sub-subcontractor acknowledged that most of the requests for change order work was prompted by verbal authorizations, including written authorizations. Shortly thereafter, the subcontractor disputed the change order requests and claimed that the sub-subcontractor performed work without signed change orders.  The prime contractor and its Miller Act payment bond surety disputed the sub-subcontractor’s payment bond claim contending the sub-subcontractor never complied with its subcontract by not obtaining prior written approval in a change order before performing the change order work.

 

Here, the trial court held that the subcontractor waived the subcontract’s requirement that change orders be in writing signed by both parties thereby allowing the sub-subcontractor to recover against the Miller Act payment bond:

 

Here, Agate [sub-subcontractor] has presented evidence that American Steel [subcontractor] waived the requirement that change orders be approved in a writing signed by both American Steel and Agate. Agate presented change orders and T&M summaries for payment. In his June 18 email, American Steel’s president, Williamson, approved a revised contract amount of $126,907.00. He also directed Agate to proceed with work as soon as possible and asked how soon Agate could return to the work site. Agate subsequently performed more work on the project based on the approval of the change orders. No issue of fact remains that the parties therefore waived the requirement that the change orders be in a writing signed by both parties.

 

Ideally this issue would never arise because the parties would comply with the strict requirements of the contract and change orders would never be performed without there being a signed change order.  But we all know that this does not always happen leading to disputes relating to change orders after the work is already performed.  While such strict language is certainly beneficial, it is not absolute and the party performing the change order work can navigate around the strict requirements by presenting evidence establishing this requirement was waived.  Such evidence can be in the form of written authorizations to perform the work, the manner in which other change orders were handled, testimony from fact witnesses regarding oral authorizations, meeting minutes discussing the change, and other evidence that shows the party looking to enforce the requirements waived them through their course of conduct and actions.

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

 

 

A DAVIS BACON SNACK – PREVAILING MINIMUM WAGE RATES ON CONSTRUCTION PROJECTS

UnknownContractors working on federal projects should be familiar with the Davis Bacon Act (40 USC s. 3142 and formerly cited as 40 U.S.C. 276a).  This Act requires contractors to pay, at a minimum, prevailing wage rates including fringe benefits for labor as determined by the Secretary of Labor.  The wage rate for select workers is oftentimes an exhibit to the contract.  To confirm parties are complying with the Act and paying prevailing wage rates including fringe benefits, parties are responsible for submitting certified payroll certifying the rates they are paying labor.   For more information on the Davis Bacon Act and submitting certified payroll, please click here and here.

 

Violations of the Davis Bacon Act are bad!  Violations can include contract termination, fines in the form of liquidated damages, debarment from federal projects for a period of time, claims by improperly paid laborers, potential violations of the False Claims Act, and potential criminal prosecution.

 

Many local jurisdictions also have their form of prevailing wage rates that they require for the labor working on their projects.

 

By way of example, Miami-Dade County has what it refers to as “Responsible Wages and Benefits” embodied in Section 2-11.16 of its Code.  You will see minimum wage rates  for labor (e.g., glazers, carpenters, drywall finishers, electrical workers, plumbers, roofers, etc.).  Any failure to pay these minimum rates can result in fines/ penalties and the County withholding payment to cover the required payment and penalties/ fines.

 

In Broward County, Section 26-5 of the County’s Code contains “Rate of Wages, fringe benefits on county construction contracts.”   It requires minimum wages pursuant to the wages promulgated by the United States Department of Labor in the Federal Register.

 

If you are working on a federal or state or local government public construction project, make sure you know what the minimum prevailing wage rates are for labor.  Not only will this help you in accurately projecting the costs of the work, but will help to avoid harsh consequences if that labor is not paid the minimum wage rates or, worse, there is a false certification of wage rates.

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

HOME OFFICE OVERHEAD (EICHLEAY) AND GOVERNMENT-CAUSED STANDBY

images-1JMR Construction Corp. v. United States, 2014 WL 3418445 (Fed.Cl. 2014) is a good federal government contracting case discussing a prime contractor’s challenging burden to support unabsorbed home office overhead damages caused by a government-caused delay.  The United States Court of Federal Claims described unabsorbed home office overhead damages and the required elements (under the Eichleay methodology) for a prime contractor to prove these damages:

 

The term “home office overhead” refers to the general administration costs of running a business, such as accounting and payroll services, general insurance, salaries of upper-level management, heat, electricity, taxes, and depreciation. These are indirect costs, expended for the benefit of the whole business, [and thus] by their nature cannot be attributed or charged to any particular contract.

***

Contractors typically recoup these indirect costs by allocating them to individual contracts in proportion to those contracts’ direct costs. But, in the event of a government-caused delay or suspension of work, the stream of direct costs against which to assess a percentage [of home office overhead] is decreased. The resulting shortfall is termed unabsorbed home office overhead.

***

The Circuit has held that the so-called Eichleay formula is the sole method through which contractors are able to recover unabsorbed home office overhead. The Eichleay formula requires that contractors satisfy several strict prerequisites. First, the contractor must demonstrate that there was a government-caused delay not excused by a concurrent contractor-caused delay. Second, the contractor must show that it incurred additional overhead expenses, either because the contract’s performance period was extended or because the contractor would have finished prior to the un-extended performance period’s close. Third, the contractor must establish that it was required to remain on standby for the duration of the delay. [Standby does not require the prime contractor to prove that it was completely idle but that its work was significantly slowed such that it was performing minor tasks.]

***

In order to establish standby, contractors must demonstrate three things. First, the contractor must show that the government caused delay was not only substantial but was of an indefinite duration. Second, the contractor must demonstrate that, during the delay, it was required to return to work at full speed and immediately [once the suspension period is over.  If the prime contractor is given a reasonable period of time to remobilize after the suspension is lifted, it will not be able to satisfy this requirement]. Third, the contractor must show a suspension of most if not all of the contract work. If the contracting officer has issued a written stop work order proving these elements the contractor can utilize that order to provide direct evidence of standby. Otherwise, these elements can be proven through indirect evidence.

***

If the contractor can make a prima facie showing of the standby elements, the burden of production shifts to the government to show either that it was not impractical for the contractor to obtain replacement work during the delay, or that the contractor’s inability to obtain or perform replacement work was caused by a factor other than the government’s delay.

JMR Construction, supra, at *5-7 (internal quotations and citations omitted); see also P.J. Dick, Inc. v. Principi, 324 F.3d 1364 (Fed.Cir. 2003) (finding that contractor could not support claim for unabsorbed home office overhead as it could not support it was on standby).

 

The Federal Circuit Court of Appeals summarized these requirements by the following questions:

 

In short, a court evaluating a contractor’s claim for Eichleay damages should ask the following questions: (1) was there a government-caused delay that was not concurrent with another delay caused by some other source; (2) did the contractor demonstrate that it incurred additional overhead…; (3) did the government CO [contracting officer] issue a suspension or other order expressly putting the contractor on standby; (4) if not, can the contractor prove there was a delay of indefinite duration during which it could not bill substantial amounts of work on the contract and at the end of which it was required to be able to return to work on the contract at full speed and immediately; (5) can the government satisfy its burden of production showing that it was not impractical for the contractor to take on replacement work (i.e., a new contract) and thereby mitigate its damages; and (6) if the government meets its burden of production, can the contractor satisfy its burden of persuasion that it was impractical for it to obtain sufficient replacement work. Only where the above exacting requirements can be satisfied will a contractor be entitled to Eichleay damages.

P.J. Dick, Inc. v. Principi, 324 F.3d 1364, 1373 (Fed.Cir. 2003).

 

In JMR Construction, the prime contractor was hired to build an aircraft maintenance facility.  The prime contractor sued the government pursuant to the Contract Disputes Act for government-caused delays. The period of delay the prime contractor was seeking to recover damages for was January 16, 2009 (day after the government occupied the facility) through September 4, 2009 (completion).

 

 

The government took occupancy of the facility on January 15, 2009.  The prime contractor continued to perform work after this date, although its workforce slowed down.   On February 3, 2009, the prime contractor demobilized its jobsite trailer and was finishing the balance of its work including the manufacturing and installation of a permanent power converter and the installation of ceiling lights in one of the rooms.  Temporary stopgap measures had been implemented to address these electrical issues that likely allowed the government to utilize the facility.

 

The government moved for summary judgment as to the prime contractor’s entitlement to unabsorbed home office overhead damages. The Court broke the prime contractor’s unabsorbed home office overhead claim into two discrete periods: (1) January 16, 2009 (day after the government took occupancy) to February 3, 2009 (when the contractor demobilized jobsite trailer) and (2) February 4, 2009 to September 4, 2009 (period when the permanent power and room lighting were being installed).  Because the contracting officer never issued a standby notice, the prime contractor had the burden to prove by indirect evidence the factors (referenced above) supporting its entitlement to unabsorbed home office overhead.

 

First Period: 1/16/09-2/3/09

 

The Court did not grant summary judgment during this period because there was a disputed issue of fact as to materiality of the work the prime contractor was performing during this time period.  The prime contractor contended the work it was performing was minor whereas the government contended the work was material. If the work is deemed material (or more than just minor tasks) the prime contractor’s unabsorbed home office overhead claim will fail since it was never on standby or suspended.  If it was minor, the prime contractor would still need to prove the elements of standby. Although the Court declined to grant summary judgment based on this disputed factual issue, it seems from the Court’s ruling during the second time period (below) that the prime contractor will have difficulty proving the elements of standby.

 

Second Period: 2/4/09-9/4/09

 

The Court granted summary judgment on the prime contractor’s claim for unabsorbed home office overhead during this period because the prime contractor could NOT prove the elements of standby. In particular, the prime contractor could not prove it was required to resume work at full speed and immediately once the “suspension period” was over.  The prime contractor did not appear to maintain any personnel or equipment on site during this period that eliminated any argument that it was required to return to work with any degree of urgency once the suspension was lifted.  The prime contractor also utilized a subcontractor to perform the incomplete electrical work, and the use of subcontractors can limit a prime contractor’s ability to prove standby since it was only monitoring the work and not actually required to return to work at all.  And last, temporary stopgap measures were implemented relating to the lighting that negated the time sensitivity of the remaining work meaning there was no urgency for the contractor to resume work immediately.

 

Eichleay-formulaFinally, even assuming the prime contractor could support its entitlement to unabsorbed home office overhead, the Court did not go into any discussion regarding the Eichleay formula–the specific formula utilized to determine the allocable unabsorbed home office overhead associated with a government-caused delay.  The objective of the Eichleay formula is to obtain a daily rate for the home office overhead allocated to the specific contract and multiply the daily rate by the number of delay days to determine the contractor’s unabsorbed home office overhead caused by the government’s delay.

 

 

 

 

 

 

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

CONSTRUCTION RENTAL EQUIPMENT SUPPLIERS AND THE ENFORCEMENT OF LIEN RIGHTS

imagesConstruction rental equipment suppliers play a large role in the performance of construction projects, whether it is through furnishing a crane, barge, excavator, scissor lift, scaffolding, loader, compressor, generator, shoring, pump, etc. Routinely, the trade subcontractor that needs the equipment to perform its contractual scope of work procures the rental equipment.

 

Well, how do these rental equipment suppliers enforce lien rights on private projects if they remain unpaid?

 

To begin with, they need to serve preliminary notices such as the Notice to Owner within 45 days from initial furnishing, which is the date rental equipment is delivered to the site.  The lien must then be recorded within 90 days from final furnishing, which is the last date the rental equipment is on the job site and available for use.  These dates should (hopefully) be pretty easy to determine as suppliers document the date rental equipment was delivered to the job site and the date the equipment was picked-up from the job site.  If not, these dates should be obtained by the renting party’s records.

 

Before recording the lien, the rental equipment supplier needs to determine the lien amount. The rental equipment supplier will typically lien for the entire amount of the rental equipment it furnished to the renting party / lessee for the project pursuant to the contractual rate(s) in the rental agreement.  This is generally the appropriate strategy because Florida’s Lien Law provides in pertinent part:

 

The delivery of rental equipment to the site of the improvement is prima facie evidence of the period of the actual use of the rental equipment from the delivery through the time the equipment is last available for use at the site, or 2 business days after the lessor of the rental equipment receives a written notice from the owner or the lessee of the rental equipment to pick up the equipment, whichever occurs first.”

Fla. Stat. s. 713.01(13). 

 

This language is important to the rental equipment supplier because if the supplier has the documentation as to when the rental equipment was delivered and picked-up, then this should shift the burden to the owner to prove that the rental equipment was not actually used on the project to diminish the amount of the lien.

 

Notably, the language in Florida’s Lien Law regarding rental equipment used to provide: “to the extent of the reasonable rental value for the period of actual use (not determinable by the contract for rental unless the owner is a party thereto),” meaning that the onus was on the rental equipment supplier not in privity with the owner to determine actual usage of the equipment on the project and the reasonable value for the period the equipment was actually used on the project.  This verbiage has since been removed from Florida’s Lien Law (in 2007), such that burden is really shifted to the owner to prove that the equipment was not actually used on the job site irrespective of when it was delivered and when it was picked-up.  While an owner may still argue that the supplier must also prove the “reasonable value” of the equipment actually used on the job site (with the reasonable value differing from the contract rental rate), this argument is based on the statutory language and case law interpreting the verbiage that has since been removed from Florida’s Lien Law. See, e.g., Rosenholz v. Perrine Development Co., 340 So.2d 1264 (Fla. 4th DCA 1976) (interpreting older version of Fla. Stat. s. 713.01 and finding that contractual rental rate, although unchallenged, did not support the reasonable rental value because the supplier did not introduce evidence of the reasonable, actual use of the equipment required for the lessee’s scope of work).  In other words, to the extent the owner wants to maintain this argument, it really should have the burden challenging (a) the actual use of the equipment, perhaps by resorting to daily reports showing the equipment was not actually used and (b) the reasonable rental value should be different than the contractual rental rate based on evidence supporting this position.

 

Now, even under the older verbiage in Florida’s Lien Law, a rental equipment supplier did not have to jump through hoops in an action against a payment bond for a private project (issued per Florida Statute s. 713.23) to prove both the actual use of the rental equipment and the reasonable rental rate for that equipment.  See, e.g., Insurance Co. of N. America v. Julien P. Benjamin Equipment Co., 481 So.2d 511, 513 (Fla. 1st DCA 1985) (“We distinguish from this [language in the payment bond] the language found in the statute [Fla. Stat. s. 713.01], which, in our view, is substantially more restrictive and clearly requires actual proof of the time of use of rental equipment and the reasonable value thereof unless the owner of the project is shown to have been a party to the rental contract covering such equipment.”).

 

Therefore, it is important for the rental equipment supplier to keep records documenting the delivery date and pick-up date from the specific project in which it plans to lien.  The owner, especially an owner that did not contract for the rental equipment, needs to obtain this information and, to the extent there are daily reports from the lessee (party that rented the equipment), cross-reference the equipment with the daily reports to examine when the equipment was actually used.  While the owner may still choose to argue the “reasonable rental value” for the equipment based on “actual usage,” this burden should fall on the owner with evidence supporting the reasonable rental value the owner believes should apply based on actual usage.  Sometimes, even though these arguments may have teeth, it may be efficient for the owner to negotiate a resolution with respect to equipment it recognizes was utilized on its project in the performance of the work.

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

TIME EXTENSIONS FOR “UNUSUALLY SEVERE WEATHER” ON FEDERAL PROJECTS

imagesWhat do you do if you encounter unusually severe weather? A time extension for unusually severe weather conditions is set forth under the default clause (such as 48 CFR 52.249-10) included in federal government construction contracts.

 

The clause typically provides in pertinent part:

 

“(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include (i) acts of God or of the public enemy, (ii) acts of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.” 

48 CFR 52.249-10; see also 48 CFR 52.249-14 (regarding unusually severe weather as an excusable delay).

 

As reflected above, unusually severe weather is an excusable delay that will entitle the contractor to additional time to peform, but not additional compensation. However, not every weather event amounts to unusually severe weather. In order to be entitled to an extension of time for weather conditions, the contractor must produce evidence of the unusually severe weather event that it contends entitles it to additional time to perform. Edge Const. Co., Inc. v. U.S., 95 Fed. Cl. 407, 420 (Fed.Cl. 2010). “Unusually severe weather must be construed to mean adverse weather which at the time of year in which it occurred is unusual for the place in which it occurred. This condition is not established simply because weather charts may indicate that on a certain day the precipitation is greater than on some other days in some other year, since variance in weather patters is to be expected.” Broome Const., Inc. v. U.S., 492 F.2d 829, 835 (Ct.Cl. 1974). “Thus, unusually severe weather is determined based on a comparison of the conditions experienced by the contractor and the weather conditions of prior years.” Edge Const., 95 Fed.Cl. at 420.  Without proving that unusually severe weather impacted performance, the “delay was anticipated and agreed to by the parties…the Government [owner] is not obligated to anticipate acts of God and abnormal conditions that might interfere with contract performance. It is supposed that bidders allow for this in their bids.” Broome Const., 492 F.2d at 835.

 

Proving that there was unusually severe weather oftentimes requires providing weather data from the National Oceanic and Atmospheric Administration (“NOAA”) (sometimes in conjunction with expert testimony). NOAA is a federal agency that maintains past weather data and generates future weather forecasts. Sometimes there is an actual weather clause in the contract that provides baseline weather conditions for the project location obtained from NOAA to be used as a baseline for weather time evaluations.

 

The key is that if a contractor experiences an unusually severe weather condition that impacts its performance, it has the burden to support this weather condition (again, typically with data from NOAA) and timely notify the government / owner of the weather condition. A major reason to do this is that the contractor will want the time extension in order to extend the substantial completion date of the project which is the date that triggers the government’s assessment of liquidated damages if the contract is not substantially completed / performed by a specified date.

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

AN OWNER’S “INTENDED THIRD PARTY BENEFICIARY” STATUS UNDER A SUBCONTRACT

Unknown-3Sometimes, during a dispute, there are arguments as to whether an owner is an INTENDED third party beneficiary of the subcontract by and between the general contractor and the subcontractor. There are instances where an owner desires to be an intended third party beneficiary of a subcontract so that it could pursue a breach of contract claim directly against the subcontractor. (These instances can relate to concerns over the solvency of the general contractor and/or the insurance coverage limits of the general contractor.)

 

A party is an intended [third party] beneficiary only if the parties to the contract clearly express, or the contract itself expresses, and intent to benefit the third party or a class of persons to which that party claims to belong.” Dingle v. Dellinger, 2014 WL 470679, *1 (Fla. 5th DCA 2014).  In other words, an intended third party beneficiary is not a signatory or party to the contract. Rather, it is expressly clear from the contract that the contract’s intent is to directly benefit that third party. Dingle, 2014 WL at *1 (finding to assert a breach of an intended third party beneficiary contract, the third party must show an intent that the contract was to directly and primarily benefit the third party). Because the intent of the contract is to directly benefit the third party, the third party is entitled to enforce the contract and, thus, sue for a breach of that contract.

 

However, if a third party is not an intended third party beneficiary of the contract, it will be deemed an incidental beneficiary that maintains no rights whatsoever to enforce the contract. McKinney-Green, Inc. v. Davis, 606 So.2d 393, 396 (Fla. 1st DCA 1992).

 

Now, a property owner is typically not regarded as an intended third party beneficiary of a subcontract between a general contractor and subcontractor. See J.W. Hodges Drywall, Inc. v. Mizner Falls, LLP, 865 So.2d 681 (Fla. 4th DCA 2004) (owner could not enforce arbitration provision in subcontract between general contractor and drywall subcontractor); accord Lillibridge Health Care Services, Inc. v. Hunton Brady Architects, P.A., 2010 WL 3788859 (M.D. Fla. 2010) (owner not intended third party beneficiary of mechanical engineer’s subconsultant agreement with architect); City of Tampa v. Thornton-Tomasetti, P.C., 646 So.2d 279 (Fla. 2d DCA 1994) (public owner not intended third party beneficiary of subconsultant’s agreement between subconsultant and architect); Vogel Bros. Bldg. Co. v. Scarborough Constructors, Inc., 513 So.2d 260 (Fla. 2d DCA 1987) (public owner not intended third party beneficiary of subcontract). Indeed, the Fifth District of Florida maintained: “As one court put it, ‘[a]lthough the work performed by subcontractors ultimately accrues to the property owner, the owner is ordinarily regarded as only an incidental beneficiary of the subcontract.” Publix Super Markets, Inc. v. Cheesbro Roofing, Inc., 502 So.2d 484, 488 (Fla. 5th DCA 1987) (superseded on other grounds) quoting National Cash Register Co. v. Unarco Indus., Inc., 490 F.2d 285, 286 (7th Cir. 1974). In addition, a subcontractor is not going to be deemed an intended third party beneficiary between the prime contract between the owner and the general contractor that would entitle it to assert a breach of contract claim against the owner. Esposito v. True Color Enterprises Const., Inc., 45 So.3d 554 (Fla. 4th DCA 2010).

 

If an owner wants to be an INTENDED third party beneficiary of the subcontracts, it should require the general contractor to include certain buzz language in the subcontracts that expressly sets forth this intent. Such buzz words would be something to the effect:

 

“It is understood and agreed that this subcontract is to primarily and directly benefit the Owner; therefore, the Owner is deemed an intended third party beneficiary of the subcontract and can enforce the subcontract as an intended third party beneficiary.”

 

 

This language clearly indicates the required intent for the intended third party beneficiary status that will enable the owner to enforce the subcontract. Without such language that clearly articulates this intent, an intended third party beneficiary status should not be extended to all situations where an owner decides to sue a subcontractor for breach of subcontract when the subcontractor was not hired by the owner. Although the owner will make the argument that the subcontractor’s work is to benefit the owner under the subcontract, the subcontractor could make a similar argument that the owner’s payment obligations to the general contractor under the prime contract is to benefit the subcontractors since the owner knew that the general contractor was not self-performing the work. If however the owner is an intended third party beneficiary of the subcontract and enforces the subcontract, it should be deemed bound by all of the terms, conditions, and burdens of the subcontract. See Woods v. Christensen Shipyards, Ltd., 2005 WL 5654643 (S.D.Fla. 2005); accord Consolidated Bathurst, Ltd. v. Rederiaktiebolaget Gustaf Erikson, 645 F.Supp. 884, 886 (S.D.Fla. 1986).

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

PAY ATTENTION TO THE RELEASE YOU EXECUTE!

UnknownPay attention to the release you execute! This includes the release that is executed in consideration of insurance proceeds where the release will likely include a full release of all claims and the parties forbear from pursuing legal claims against one another. Such claims would include the insured / party receiving insurance proceeds releasing its right to assert claims for additional proceeds arising from same incident and the insurer releasing its right to assert a claim that the insured breached the insurance policy and/or that there is no coverage under the policy. This is besides the fact that the monetary payment should constitute sufficient consideration for a full release of any and all rights / claims relating to the incident.

 

In Crystal Colony Condominium Ass’n, Inc.v. Aspen Specialty Ins. Co., 2014 WL 1116881 (S.D.Fla. 2014), an insurer issued a property insurance policy to an association. In October 2005, the insured-association experienced severe damage due to Hurricane Wilma. Due to the damage, the insurer agreed to pay $1,071,359.52 to its insured-association in consideration of a full release from the insured. The insured-association agreed and a release was executed that read:

 

“In consideration of the sum of [$1,071,349.52], to me/us [Plaintiff] paid, the receipt whereof is hereby acknowledged, l/we, [Plaintiff] (being of lawful age) do hereby release and forever discharge [Defendant, its] heirs, administrators, executors, successors and assigns, from any and all action, causes of action, claims and demands whatsoever for, upon, or reason of any damage, loss or injury and all consequential damage, which heretofore have been or which hereafter may be sustained by me/us [Plaintiff] in consequence of windstorm damage during Hurricane Wilma, 10/24/05.”

It is being further agreed and understood that the payment of said amount is not to be construed as an admission of liability, but is a compromise of a disputed claim and that this release is executed in full settlement and satisfaction of rights of the undersigned under Policy No. BP000106 arising out of said hurricane damage above referred to.”

Crystal Colony, supra, at *2.

 

Approximately six year later, the insured-association advised the insurer that it disagreed with the quantum of insurance proceeds it received and filed a declaratory action. The insurer moved for summary judgment based on the full release it received for the incident (the hurricane). The insured-association argued that the release was not enforceable because it lacked consideration since the money it received was only a partial payment and did not cover future damages the association incurred. The insurer argued that the release included language where there was a mutual forbearance from pursuing legal action against the other party and this constituted more than sufficient consideration.

 

The Southern District agreed with the insurer (entering summary judgment against the association-insured) and held: “Florida law provides that a promise, no matter how slight, can constitute sufficient consideration so long as a party agrees to do something that they are not bound to do. Forbearing the pursuit of a legal remedy constitutes such a promise.” Crystal Colony, supra, at *3 (internal citations and quotations omitted).

 

Unambiguous releases will typically be deemed enforceable since it will clarify the intent of the parties. Whether it is a release given in consideration of insurance proceeds or a release given in consideration of a progress or final payment, if the party giving the release wants to ensure certain rights are carved-out or preserved, they need to do so. If the other party is unwilling to accept such carved-out language, the party giving the release, at a minimum, needs to preserve its rights by sending contemporaneous documentation that they are signing the release because the other party will not accept a release with carve-outs for the following specific issues. And, as seen from this case, if a mutual release is given where both parties forbear from pursuing claims against the other, this consideration will be more than enough consideration to support the release and courts will not delve into the type of claims that the parties are potentially releasing each other from. Thus, pay attention to the release you execute so that it does not come back to haunt you later!

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.