Category Archives: Uncategorized

CONSTRUCTION DEFECT INSURANCE CONSIDERATIONS

Posted on by

images-1Construction defect cases most always involve CGL insurance consideration and claims. And they should. A contractor that received a defect claim from an owner (developer or association) will want to notify their CGL insurer to provide a defense and coverage. The contractor will also want to notify the responsible subcontractors that may be liable to the contractor for the owner’s claims as well as the subcontractors’ CGL carriers. The contractor will do so claiming the responsible subcontractor is responsible to indemnify the contractor for damage arising out of the subcontractor’s work pursuant to their contractual indemnification provision. The contractor will also claim that it is an additional insured under the subcontractor’s CGL policy (as required by the contract and hopefully confirmed by the additional insured endorsement) and the carrier is responsible for contributing to its defense and providing coverage for the negligence caused by the carrier’s insured-subcontractor.

 

The Middle District opinion in Redfish Keys Villas Condominium Association, Inc. v. Amerisure Insurance Co., 2014 WL 92710 (M.D.Fla. 2014), illustrates certain CGL considerations. In this dispute, a general contractor was hired by a developer to construct a condominium. After the condominium was turned over to the association, leaks were discovered. The association claimed the leaks originated from defects. The association sent a construction defects notice to the contractor (pursuant to Florida Statutes Chapter 558) and the contractor failed to respond. The association then filed suit against the contractor. For whatever reason, although the contractor’s counsel filed a notice of appearance in the case, nothing else was done and a final default judgment was entered against the contractor for the damages the association incurred in repairing the leaks.

 

After the judgment was obtained, the contractor’s CGL insurer reached out to the association, apparently not realizing a judgment had been entered against its insured. Upon receiving a copy of the judgment, the insurer denied coverage based on the contractor’s failure to provide notice of the claim to the insurer. However, although not discussed in the opinion, the insurer knew about the contractor’s claim as it was the one that followed-up with the association. Most likely, the association, as it should, notified the contractor’s carrier of the defect claims although it is uncertain whether they notified the carrier of the lawsuit. Or, perhaps, the contractor, as it should, notified its carrier when it received the construction defects notice from the association.

 

The association filed suit against the contractor’s insurer in federal court for a declaratory action and for the insurer’s breach of an intended third party beneficiary contract, that being the CGL insurance policy was for the benefit of third parties such as the association. The insurer moved to dismiss the breach of intended third party beneficiary contract claim. The Middle District denied the insurer’s motion to dismiss. The Middle District found that as a condition precedent to the association suing the insurer, the association needed to comply with Florida Statute s. 627.4136 which essentially requires a third party not insured by a liability insurer to first obtain a settlement or verdict against the insured as a condition precedent to suing the insurer for coverage under the policy. The association complied with this condition precedent as it sued the insured-contractor and obtained a judgment. The Middle District further found that in Florida, “an injured third party may maintain a cause of action against an insurer as an intended third party beneficiary under a liability insurance policy.” Redfish, supra, at *3 citing Shingleton v. Bussey, 223 So.2d 713 (Fla. 1969). In other words, the MIddle District found that as long as the association complied with Florida Statute s. 627.4136 (the condition precedent to a third party suing a liability insurer statute) it could maintain a breach of an intended third party beneficiary contract claim against the CGL insurer.

 

When representing the owner, it is good practice to notify the contractor’s insurer of not only the defect claim but of any potential lawsuit (to avoid any lack of notice coverage defense, especially if the contractor does not have an attorney on board at the time of the lawsuit). Further, when representing the contractor, it is good practice to not only notify the contractor’s CGL insurer, but to notify the responsible subcontractors’ carriers of the same (based on additional insured and indemnity requirements). And, irrespective of a subcontractor’s insurer’s position, it is good practice to keep the insurers apprised of any third party lawsuit the contractor files against the insured-subcontractors (again, to avoid any lack of notice coverage defense). While the Middle District in Redfish only entered a ruling on the insurer’s motion to dismiss at this stage, the insurer’s lack of notice coverage defense will certainly be a defense that the insurer relies on in the dispute.

 

Insurance considerations are a crucial part of construction defect claims. Understanding how to preserve rights and navigate through the process cannot be overstated.

 

 

 

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

ATTORNEY’S FEES UNDER (A) FLORIDA’S DECEPTIVE AND UNFAIR TRADE PRACTICES ACT AND (B) OFFERS OF JUDGMENT

Posted on by

images

In Florida, a party can recover attorney’s fees if it has a contractual or statutory basis. If a party has neither a contractual or statutory basis to recover attorney’s fees, another vehicle is to serve an Offer of Judgment (also known as a Proposal for Settlement).  Whether there is an argument to recover attorney’s fees is an important consideration.

 

A. Attorney’s Fees Under The Florida Deceptive and Unfair Trade Practices Act

 

The Florida Deceptive and Unfair Trade Practices Act (“FDUTPA”) is a consumer-protection related law designed to allow parties to sue other parties for deceptive and unfair trade or business practices. FDUTPA is discussed in more detail in https://floridaconstru.wpengine.com/actual-damages-under-floridas-deceptive-and-unfair-trade-practices-act/. There are certain circumstances when asserting a FDUTPA claim is worthwhile and should be explored such as when a party is looking for a statutory basis to recover attorney’s fees.

 

FDUTPA contains a statutory basis to recover attorney’s fees. Section 501.2105 of FDUTPA provides in relevant part:

 

 “(1) In any civil litigation resulting from an act or practice involving a violation of this part, except as provided in subsection (5), the prevailing party, after judgment in the trial court and exhaustion of all appeals, if any, may receive his or her reasonable attorney’s fees and costs from the nonprevailing party.”

 

 

The reason the word “may” is highlighted is because this is permissive, not mandatory, language. In other words, it is not automatic or mandatory that attorney’s have to be awarded to the prevailing party, but they could (i.e., may) be awarded. This is an important distinction. However, recently, Florida decisions have indicated that attorney fees should be mandatorily awarded to the prevailing party in a FDUTPA action.

 

Recently, in Bull Motors, LLC v. Alicia Borders, 39 Fla. L. Weekly D28a (Fla. 3d DCA 2013), the Third District stated:

 

“FDUTPA’s attorneys’ fees provision recognizes the policy of protecting consumers from unfair and deceptive trade practices and the need to attract private attorneys to take such cases by assuring them of a legal fee proportionate to their effects if their clients prevail. Such an award requires that the client prevail by recovering a judgment and, if there are counterclaims, by recovering a net judgment in the entire case. There is no express requirement of proportionality between the amount of the FDUTPA judgment and the attorney’s fees and costs incurred in obtaining the judgment.”

Bull Motors, supra (internal quotations omitted).

 

 

Bull Motors relied on the Florida Supreme Court’s decision in Diamond Aircraft Indus., Inc. v. Horowitch, 107 So.3d 362 (Fla. 2013).  In Diamond Aircraft, a plaintiff asserted a FDUTPA claim against a defendant. However, it was determined that FDUTPA did not apply because Arizona law, not Florida law, governed the case. Thus, the defendant prevailed under the plaintiff’s FDUTPA claim. A question certified to the Florida Supreme Court to answer was whether FDUTPA entitled a prevailing party to attorney’s fees if the court determines that FDUTPA does not apply to the case because the substantive law of another state (in this case, Arizona) applied. The Court stated that it did (or answered the question in the affirmative) holding that by a plaintiff asserting a FDUTPA claim, it exposes itself to both the benefits and potential consequences of the statute. Further, the Court expressed: “Under FDUTPA, a prevailing party is entitled to reasonable attorney’s fees and costs in civil litigation arising from a violation of that act ‘after judgment in the trial court and exhaustion of all appeals.’” Diamond Aircraft, supra, at 370 quoting Fla.Stat. s. 501.2105.

 

Hence, even though the statute contains permissive language, there is strong legal authority that would mandatorily entitle a prevailing party to recover attorney’s fees. This cuts both ways. This means that a plaintiff could expose itself to attorney’s fees by improperly asserting a FDUTPA claim without facts to support a deceptive or unfair trade practice or without evidence to support actual damages as provided under the statute.  Plaintiffs need to be cognizant of this before asserting a FDUTPA claim.

 

B. Attorney’s Fees By Serving Offers of Judgment

 

 

 

Moreover, Bull Motors discussed the vehicle to create an argument for the recoverability of attorney’s fees known as offers of judgment or proposals for settlement (“Offer of Judgment”). The Offer for Judgment statute in Florida Statute 768.79 provides in material portion:

 

“In any civil action for damages filed in the courts of this state, if a defendant files an offer of judgment which is not accepted by the plaintiff within 30 days, the defendant shall be entitled to recover reasonable costs and attorney’s fees incurred by her or him or on the defendant’s behalf pursuant to a policy of liability insurance or other contract from the date of filing of the offer if the judgment is one of no liability or the judgment obtained by the plaintiff is at least 25 percent less than such offer….If a plaintiff files a demand for judgment which is not accepted by the defendant within 30 days and the plaintiff recovers a judgment in an amount at least 25 percent greater than the offer, she or he shall be entitled to recover reasonable costs and attorney’s fees incurred from the date of the filing of the demand.”

 

 

In a nutshell, a defendant can recover its attorney’s fees if it serves an Offer of Judgment and the plaintiff gets a $0 judgment against the defendant or the plaintiff gets a judgment of at least 25% less than the offer. For example, and using simple math, let’s say the defendant serves an Offer of Judgment for $100,000 and the plaintiff obtains a net judgment against the defendant for $50,000. In this situation, the defendant could be entitled to its attorney’s fees from the date of the Offer of Judgment and forward since the plaintiff obtained a judgment of at least 25% less than its $100,000 Offer.

 

And, if a plaintiff serves an Offer of Judgment, it can recover its attorney’s fees if gets a net judgment of at least 25% greater than the Offer. Let’s say the plaintiff serves a $100,000 Offer of Judgment and recovers a net judgment against the defendant for $150,000. In this situation, the plaintiff could be entitled to its attorney’s fees from the date of the Offer of Judgment and forward since the plaintiff obtained a judgment of at least 25% greater than its $100,000 Offer.

 

However, serving Offers of Judgment are not sure-things under Florida law that will guarantee a party to attorney’s fees even if the math (shown above) works. There are numerous Florida decisions that find defects in Offers of Judgment (including technical defects) that ultimately prevent a party from recovering its attorney’s fees. Both Bulls Motor and Diamond Aircraft are examples of decisions whereby the Courts found flaws in the Offers of Judgment. Offers of Judgment do not apply to claims for equitable relief, only claims for damages. Thus, parties need to be crystal clear that the Offers only apply to claims for damages. But it is unfortunately not that simple. The Florida Supreme Court in Diamond Aircraft stated:

 

“Courts have also held that when a plaintiff seeks both monetary and nonmonetary relief, and a party makes a general offer of settlement, section 768.79 is not applicable. The reasoning adopted in those decisions is that strict construction of the phrase “any civil action for damages” in the offer of judgment statute does not include a claim for equitable relief, or one that involves claims for both monetary and nonmonetary relief.
***
We hold that section 768.79 does not apply to an action in which a plaintiff seeks both damages and equitable relief, and in which the defendant has served a general offer of judgment that seeks release of all claims.”
Diamond Aircraft, 107 So.3d at 373-74 (internal citations omitted); accord Bull Motors, supra (“The offer of judgment statute, section 768.79…does not apply to cases that, as here, involve a general offer seeking release of all claims in the case, both equitable and monetary.”).

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

 

“CRITICAL PATH” AND “CONCURRENT DELAY” BASICS AS INTERPRETED BY COURTS

Posted on by

UnknownThe terms “critical path” or “critical path method (CPM)” are frequently used terms in construction contracts and, importantly, delay-related claims.  These terms refer to the construction schedule and the method to establish delays to the substantial completion date.  To the construction participant,  specifically project management, these terms are must-know terms and are vital to the proper planning and management of the project!  A project is composed of many individual construction activities that are all interrelated.  Each activity has a scheduled duration or the number of days for the activity to be performed.  And, many activities cannot begin until predecessor activities are completed.  Project management needs to understand and appreciate all of this in order to successfully manage a project by the milestone substantial completion date that is agreed upon on the front-end.

 

 

Now, to the non-construction participant or lay person, the terms “critical path” or “critical path method (CPM)” do not mean much because they are not used in everyday language.  However, technical terms that are not part of everyday vocabulary need to be explained so that a lay person that is not a construction participant can understand and appreciate the significance of the terms–think judge or jury!   Oftentimes, the best way to explain the critical path is to analyze  court decisions that have interpreted this term in connection with a construction dispute.  The following are construction cases that have defined or interpreted the critical path:

 

CRITICAL PATH 

 

 

“The critical path is the longest series of the work activities through the performance of a whole project. If an activity on the critical path exceeds its scheduled duration, the termination of the project will be delayed unless some other activity on the critical path is performed in less than its scheduled time. A work activity not on the critical path may be completed later than its scheduled time without affecting the termination of the project unless the non-critical activity exceeds its “float” and thereby becomes an activity on the critical path.”

U.S. Fidelity & Guar. Co. v. Orlando Utilities Com’n, 564 F.Supp. 962, 968 (M.D.Fla. 1983)

 

“The project can be represented by a network of discrete paths that sequence interdependent tasks or milestones leading to project completion. The critical path, the longest path at any point in time, determines the project’s expected completion date.” 

Gulf Contracting, Inc. v. U.S., 23 Cl.Ct. 525, 529, n.2 (Cl.Ct. 1991)

 

 

“Essentially, the critical path method is an efficient way of organizing and scheduling a complex project which consists of numerous interrelated separate small projects. Each subproject is identified and classified as to the duration and precedence of the work. (E.g., one could not carpet an area until the flooring is down and the flooring cannot be completed until the underlying electrical and telephone conduits are installed.) The data is then analyzed, usually by computer, to determine the most efficient schedule for the entire project. Many subprojects may be performed at any time within a given period without any effect on the completion of the entire project. However, some items of work are given no leeway and must be performed on schedule; otherwise, the entire project will be delayed. These latter items of work are on the critical path. A delay, or acceleration, of work along the critical path will affect the entire project.”

Haney v. United States, 676 F.2d 584, 595 (Ct.Cl. 1982)

 

“Critical Path Methodology” (CPM) is a term of art for a method of scheduling and administering construction contracts. The Court of Claims has explained that CPM enables contractors performing complex projects to identify a critical path of tasks that must each be completed before work on other tasks can proceed. A delay on the critical path will thus delay the entire project: Essentially, the critical path method is an efficient way of organizing and scheduling a complex project which consists of numerous interrelated separate small projects. Each subproject is identified and classified as to the duration and precedence of the work. (E.g., one could not carpet an area until the flooring is down and the flooring cannot be completed until the underlying electrical and telephone conduits are installed.) The data is then analyzed, usually by computer, to determine the most efficient schedule for the entire project. Many subprojects may be performed at any time within a given period without any effect on the completion of the entire project. However, some items of work are given no leeway and must be performed on schedule; otherwise, the entire project will be delayed. These latter items of work are on the “critical path.” A delay, or acceleration, of work along the critical path will affect the entire project.”

Morrison Knudsen Corp. v. Fireman’s Fund Ins. Co., 175 F.3d 1221, 1232-1233 (10th Cir. 1999)  (internal citations and quotations omitted)

 

 

As explained, construction schedules contain numerous activities that are interdependent on one another and are required to complete the project.  Each activity contains a duration required to complete the given activity.  Schedules typically identify the milestone of substantial completion.  Most schedules identify the critical path by tracking the longest duration path  through the activities to achieve completion.  If an activity on the critical path is not completed on time, it will delay the completion date.  Sophisticated scheduling software allows contractors to identify each activity’s early start date (earliest time an activity can start provided its predecessor activities are performed), early finish date (simply taking the early start time plus the scheduled duration), late start date (the latest time an activity can start without delaying the completion date by factoring in the scheduled duration), and late finish date (simply taking the late start time plus the scheduled duration).  By showing the early start date and late start date, project management is able to determine the float time with the activity.  In other words, if an activity has both an early start and late start date, the float allows an activity to be delayed from its early start date to its late start date without actually delaying the completion date of the project.  Naturally, there is much more to construction scheduling and determining the critical path (or revising the critical path during the course of construction) than this!  The point is that the critical path, as interpreted in the cases above, is critical because this is really how delays are proven on a construction project (whether the delays are used to offset liquidated damages, establish an entitlement to extended general conditions, or flow down extended general conditions and liquidated damages to the trade subcontractor responsible for the delay):

 

CRITICAL PATH USED TO PROVE DELAYS 

 

 

“Contractors have the burden of proving delays attributable to the Government. It may be impossible to establish government-caused [owner-caused] delays without a means of showing the critical path.”

Daewoo Engineering and Const. Co., Ltd. v. U.S., 73 Fed.Cl. 547 (Fed.Cl. 2006)

 

“In order to prevail on its claims for the additional costs incurred because of the late completion of a fixed-price government construction contract [owner contract], the contractor must show that the government’s [owner’s] actions affected activities on the critical path  of the contractor’s performance of the contract.  The reason that the determination of the critical path is crucial to the calculation of delay damages is that only construction work on the critical path had an impact upon the time in which the project was completed.  One established way to document delay is through the use of Critical Path Method (CPM) schedules and an analysis of the effects, if any, of government-caused events upon the critical path of the project.”

George Sollitt Const. Co. v. U.S., 64 Fed.Cl. 229, 240 (Fed.Cl. 2005) (internal citations and quotations omitted)

 

Sometimes, there are concurrent delays to the project occurring at the same time that both impact / delay the completion date.   Concurrent delays have been defined by courts as:

 

CONCURRENT DELAYS AND APPORTIONMENT 

 

 

 “The doctrine of concurrent delay involves the premise that where both parties to the litigation caused delays then neither party can recover damages for that period of time when both parties were at fault.”

Broward County v. Russell, Inc., 589 So.2d 983, 984 (Fla. 4th DCA 1991)

 

 

“Where both parties contribute to the delay neither can recover damage, unless there is in the proof a clear apportionment of the delay and the expense attributable to each party.”

Blinderman Const. Co., Inc. v. U.S., 695 F.2d 552, 559 (Fed.Cir. 1982) (internal citation and quotation omitted)

 

 

“Courts will deny recovery where the delays are concurrent and the contractor has not established its delay apart from that attributable to the government.”

William F. Klingensmith, Inc. v. U.S., 731 F.2d 805, 809 (Fed.Cir. 1984)

 

 

“[C]ontractor may not collect damages from the government due to delay where that contractor was itself in a state of concurrent delay. Generally, courts will deny recovery where the delays are concurrent or intertwined.  Even where both parties are responsible for delay, a contractor may not recover unless it is able to apportion the delay and expense attributable to each party.The burden of apportioning delay falls on the plaintiff. Courts will deny recovery where delays are concurrent and the contractor has not established its delay apart from that attributable to the government.”

Smith v. U.S., 34 Fed.Cl. 313, 325 (Fed.Cl. 1995) (internal citations and quotations omitted)

 

 

“The general rule barring recovery for government-caused unreasonable delay when there has been concurrent delay caused by the contractor does permit recovery, however, when clear apportionment of the delay attributable to each party has been established. Because the equitable adjustment claim for compensable delay is the contractor’s claim, the burden is on the contractor to apportion the delay between the parties. Generally, courts will deny recovery where the delays  are concurrent or intertwined and the contractor has not met its burden of separating its delays from those chargeable to the Government.”

George Sollitt Const. Co. v. U.S., 64 Fed.Cl. 229, 238-39 (Fed.Cl. 2005) (internal citations and quotations omitted)

 

 

This articles covers just the basic elements of critical path and concurrent delay based on interpretations from Florida and federal courts.  Understanding these terms and how courts have interpreted these terms is important so parties know what they need to do to prove a delay (and how they need to prove the delay and sustain their burden of proof) based on the factual dynamics and circumstances of their dispute.  Without this understanding, parties are not in the best position regarding developing strategy and themes associated with their case to assist is persuasively presenting testimony / evidence to support their position.

 

For more information on substantial completion, please see: https://floridaconstru.wpengine.com/what-is-substantial-completion/

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

THE IMPORTANCE OF SAFETY

Posted on by

imagesParticipants in construction NEED to have safety programs and protocols. Many contractors do in order to minimize injury and prevent death and many even employ a safety officer on their projects. Safety protocols are also important to ensure compliance with the Occupational Safety and Health Administration’s (OSHA) health and safety regulations. Safety programs and common contractual provisions require parties to keep their work environment clean and without debris. For example, section 3.15.1 of the AIA A201 General Conditions (2007) provides:

 

“The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. At completion of the Work, the Contractor shall remove waste materials, rubbish, the Contractor’s tools, construction equipment, machinery and surplus materials from and about the Project.”

 

Safety programs are not only important for contractors and subcontractors, but also for those invitees that are invited to the construction project. The case of Skala v. Lyons Heritage Corp., 38 Fla. L. Weekly D2485b (Fla. 2d DCA 2013), exemplifies what can happen if an invitee of a general contractor gets injured from construction debris. In this case, the general contractor on an ongoing residential project was interested in hiring a new tile installer for the project. There was an issue with the performance of the original tile installer.  The new tile installer was asked to inspect the installed tile work in order to provide an estimate as to what it would cost to fix and complete the work. A contract was not executed and there was no confirmation that a price would even be reached.  During the inspection, the new tile installer tripped and fell on known and obvious construction debris while entering the house and suffered fractures in both of this arms. The new tile installer sued the general contractor for negligence asserting that the contractor failed to maintain the premises in a safe condition. The trial court entered summary judgment in favor of the general contractor.

 

On appeal, the Second District found that the new tile installer was a business invitee (i.e., a person invited to property by the possessor of the property)–”because Mr. Skala [new tile installer] was a business invitee on the property, Lyons Heritage [general contractor], as the possessor of the premises, owed him a duty, as a matter of law, to maintain the premises in a reasonably safe condition.” Skala, supra (internal quotation omitted).

 

The general contractor, however, would not be liable for injuries caused by known or obvious dangers, such as the known and obvious construction debris, unless it should have anticipated the injuries despite the known or obvious nature of the dangers. This is referred to as the obvious nature doctrine: “The obvious danger doctrine provides that an owner or possessor of land is not liable for injuries to an invitee caused by a dangerous condition on the premises when the danger is known or obvious to the injured party, unless the owner or possessor should anticipate the harm despite the fact that the dangerous condition is open and obvious.” Skala, supra, quoting DeCruz-Haymer v. Festival Food Mkt., Inc., 117 So. 3d 885, 888 (Fla. 4th DCA 2013).  Stated differently, the possessor of the property can be held liable for the obvious dangerous condition if he can reasonably foresee that the condition will cause harm and will be encountered by the invitee. Id. quoting Ahl v. Stone Sw., Inc., 666 So. 2d 922, 925 (Fla. 1st DCA 1995) (“A reasonable probability to expect harm to an invitee from known and obvious dangers may arise . . . if the landowner may expect that the invitee will encounter the known or obvious danger, because, to a reasonable person in the invitee’s position, the advantages of [facing the danger] would outweigh the apparent risk.”)

 

The Second District reversed the summary judgment finding an issue of fact existed as to whether the exception to the obvious danger doctrine applied, that being that the general contractor should have anticipated that the new tile installer would encounter the known and obvious construction debris because, to a reasonable person in the installer’s position, the advantages of facing the construction debris would outweigh the risk.

 

If the construction debris was not known and obvious to the new tile installer, the general contractor would have also been sued in negligence under a theory that it breached its duty of warning the new tile installer of a latent dangerous condition. See Skala, supra, n. 3 (finding that the general contractor had the duty to warn the new tile installer / invitee of latent dangerous conditions).

 

This case illustrates one example of the importance of safety.   Safety programs should not be taken lightly!   Sometimes, with business invitees, it is good practice to have them provide a release before they enter the property to the owner, contractor, and applicable parties.

 

As an aside, the Concrete Construction Magazine in November 2013 tweeted an interesting 2010 statistic from the United States Department of Labor (the OSHA agency falls within the Department of Labor) itemizing the most common OSHA violations in 2010 were for scaffolding, fall protection, stairways and ladders, personal protective equipment, electrical, health hazards, general provisions, and trenching.

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

A LANDLORD’S REFUSAL TO TIMELY PERFORM NEEDED REPAIRS / MAINTENANCE ITEMS

Posted on by

imagesWhat happens if the landlord refuses to timely repair defects or perform necessary maintenance items that it is otherwise responsible to perform per the lease? What happens if the landlord makes rental space untenantable? The case of Katz Deli of Aventura, Inc. v. Waterways Plaza, LLC, 38 Fla. L. Weekly D2511b (Fla. 3d DCA 2013), illustrates the issue of “constructive eviction” and a tenant’s recourse against its landlord including its recovery of lost profits when a landlord does not timely implement needed repairs that impacts a tenant’s business.

 

In this case, a successful deli in Pembroke Pines opened a new location in a shopping plaza in Aventura. After a couple of years of growing revenue, the deli leased larger space within the same Aventura plaza. The lease for the larger space was for five years, with 3% annual rent increases, and with three lease renewal options for five-year terms. Of importance to this case, the landlord was required to make all of the required repairs to the shopping plaza’s structure and roof.

 

After the execution of the lease, the shopping plaza was purchased by the defendant-landlord (which assumed the deli’s existing lease). The new landlord learned exercising its due diligence of inspecting the plaza’s condition prior to purchase that the roof needed to be replaced (re-roofed). Yet, even though it purchased the plaza, it did not timely replace the roof. As a result, leaks started at the deli and became progressively worse resulting in mold and a musty odor in the deli. Naturally, this condition caused the deli to lose business and customers and reached the point where the deli could not continue to operate as a restaurant. Then, suspiciously, after the deli vacated the space, the landlord decided to re-roof the space and found new tenants that leased the space at a much higher rental rate.  The deli sued the landlord for breach of lease (breach of contract) and constructive eviction.

 

The deli argued that the landlord constructively evicted it in order to capitalize on substantially higher rental rates because the agreed-upon rental rate in the lease that the deli entered into with the former landlord (and that the defendant assumed when it purchased the plaza) was well below market rate.

 

At a bench trial, the deli argued that its damages consisted of lost profits. It utilized an accounting expert to prove lost profits. The landlord contended that lost profits was not the proper damages methodology and the deli should have proven its damages by analyzing the market value of the deli since the deli was destroyed. The reason the landlord argued this is because the deli put on no evidence as to these damages (meaning, if this was the proper methodology, the deli would be entitled to no damages because it failed to put on any evidence of these damages). The trial court found that the deli was entitled to lost profits but only awarded lost profits through the end of the initial lease term, and not the three five year lease renewal options.

 

On Appeal, the Third District Court of Appeal maintained:

 

“A constructive eviction constitutes a breach of the covenant of quiet enjoyment. Furthermore, Waterways’ [landlord] grossly negligent failure to repair the roof as required by the lease was a breach of its contract. In an action for breach of contract, the goal is to place the injured party in the position it would have been in had the other party not breached the contract so as to give the aggrieved party the benefit of its bargain. However, a successful plaintiff is not entitled to be placed, because of that breach, in a position better than that which he would have occupied had the contract been performed. The injured party may only recover those damages that naturally flow from the breach and can reasonably be said to have been contemplated by the parties at the time that the contract was made. It is not necessary that the parties have contemplated the exact injury that occurred as long as the actual consequences could have reasonably been expected to flow from the breach.”

Waterways Plaza, supra (internal citations and quotations omitted).

 

When dealing with the issue of a landlord constructively evicting its tenant, there are cases that hold that the measure of damages is the market value of the business as of the date of loss when the business is completely destroyed. This is why the landlord argued that this should have been the damages methodology employed by the deli. “However, where, as here, a business [the deli] continues after suffering from an act of negligence the business is entitled to recover the lost profits attributable to defendant’s [landlord] negligent act, but cannot recover both lost profits, and the market value of the business.” Waterways Plaza, supra (internal quotations omitted).

 

The deli was not completely destroyed when the leaks started. Rather, the leaks progressed over a period of time until the space was untenantable. Largely for these reasons, there was no bright line test as to when the deli was completely destroyed. As the Third District explained: “Awarding market value for a business that has been slowly reduced to nothing due to a defendant’s breach, thereby leaving the plaintiff without an adequate recovery, would be completely inequitable, and is not the law in Florida.” Waterways Plaza, supra.

 

Since lost profits was the proper damages methodology, the Third District next analyzed whether the deli sufficiently proved such damages during the trial.

 

“Lost profits are recoverable regardless of how well established a business is so long as there is some ‘yardstick’ by which prospective profits can be measured.
***
A business can recover lost prospective profits regardless of whether it is established or has any ‘track record.’ The party must prove that 1) the defendant’s action caused the damage and 2) there is some standard by which the amount of damages may be adequately determined.
***
Any ‘yardstick’ used to show the amount of profits must be reasonable, and the loss of the profits as a result of the [defendant’s conduct] must be reasonably certain. Lost profits must be established with a reasonable degree of certainty and must be a natural consequence of the wrong. The projected profits cannot be mere speculation or conjecture, but the inability to prove a precise damages amount will not prevent a plaintiff from recovering so long as it is clear that some loss resulting from the defendant’s actions is certain.”

Waterways Plaza, supra.

 

The deli was able to establish a yardstick because it had another location in Pembroke Pines, had success at its former smaller space within the same shopping plaza, and had limited success during the short time it was in the larger space prior to the leaks. Thus, it was able to demonstrate a history of sales that enabled its expert to establish sale projections and projected profit.

 

Even though lost profits was the proper damages methodology, the deli wanted lost profits that extended through all lease renewals. The deli argued it clearly would have renewed the lease based on the success at that location and plaza prior to the leaks, because its rent was well below market rate, and because the successor tenants leasing the same space after the re-roof were still leasing the space close to ten years after the deli vacated the space. Despite this evidence, the Third District held that this was a question of fact to be determined by the trier of fact, and because the fact finder was the judge, the judge’s fact finding will be presumed correct on appeal unless clearly erroneous. Since the trial judge found that lost profits extending beyond the original five year lease term was speculative, the Third District affirmed the court’s fact finding because it was not clearly erroneous.

 

Notably, the deli also tried to foreclose an equitable lien and recorded a lis pendens against the shopping plaza. The deli’s equitable lien theory was based on the following language in the lease: “Tenant shall look solely and only to the Landlord’s interest in the Plaza in the event of any default or breach.” Waterways Plaza, supra. However, the lis pendens was discharged and the equitable lien claim was dismissed by the trial court. The deli appealed this arguing that the dismissal of the lis pendens to foreclose its equitable lien was error. The Third District affirmed the trial court finding that the language in the lease did not give the tenant an interest in the landlord’s property that would entitle it to an equitable lien and lis pendens.

 

This case illustrates options a tenant has when its rental space becomes untenantable, especially due to the landlord’s failure to timely implement or perform needed repairs / maintenance items. This case further illustrates the importance of knowing and proving a party’s correct damages methodology due to a breach.  Also, considering the factual circumstances in lost profit cases, such as this case, and how a party establishes its lost profits provides future guidance to ensure that these damages are proven with their required reasonable degree of certainty!

 

 

For more information on proving lost profits, please see: https://floridaconstru.wpengine.com/proving-lost-profit-damages-with-a-reasonable-degree-of-certainty/

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

 

LEGAL COMPLEXITIES WHEN THERE IS A FAILED PROJECT

Posted on by

heavy civil photoIberiabank v. Coconut 41, LLC, 2013 WL 6061833 (M.D.Fla. 2013) is a new case involving a failed mixed-use master development (subdivision) that illustrates some of the complexities when a construction project goes bad. It is a great case discussing aspects of Florida’s Lien Law (such as liens for subdivision improvements, single claim of lien, fraudulent liens) that are important for all construction participants. It is also a great case that discusses an unjust enrichment claim for unpaid work and a slander of title claim due to a fraudulently recorded lien. While the facts and issues are lengthy, there are numerous take-aways from this case that should not be ignored and are pointed out at the end of this article.

 

 

I. The Failed Development

 

 

In this case, a developer purchased approximately 46 acres of land. The land was intended to be developed into a master development. The developer sold approximately 14 acres referred to Development Area 2 to HG Coconut. The developer was responsible for installing the necessary infrastructure outside of Development Area 2 that would be required to develop both the developer’s land and Development Area 2. (This included, among other things, widening a road and sanitary-sewer work.)

 

To construct the infrastructure, the developer hired a heavy civil contractor. Two contracts were executed. The first contract was for on-site infrastructure improvements to the developer’s land. The second contract was for off-site infrastructure improvements such as the infrastructure improvements needed to develop Development Area 2. (There was no contract between the contractor and HG Coconut, the owner of Development Area 2.)

 

Because of nonpayment, the contractor recorded a single claim of lien. The lien included Development Area 2 (owned by HG Coconut). Remember, the contractor did not have a contract with the owner of Development Area 2.

 

II. Claims against HG Coconut – the Owner of Development Area 2 – and HG Coconut’s Claims against the Contractor

 

 

The contractor filed a lawsuit and asserted an unjust enrichment claim and lien foreclosure claim against HG Coconut–the owner of Development Area 2.  HG Coconut asserted a fraudulent lien claim and slander of title claim against the contractor.

 

 

A. Unjust Enrichment

 

The contractor contended that it benefited HG Coconut (a party it did not have a contract with) through infrastructure work it performed that provided value to Development Area 2. HG Coconut argued that the unjust enrichment claim should be barred because the contractor’s work was incomplete—it did not finish all of its work. The Middle District dismissed this argument equating recovery under an unjust enrichment theory to that of recovery when a contractor substantially performs. When a contractor substantially performs / completes its work, it is entitled to the full contract price minus the owner’s right to recover damages due to the contractor’s failure to render full performance. Since the contractor substantially completed its work subject to the unjust enrichment claim that provided a benefit to Development Area 2, the Middle District held that the contractor was entitled to the fair market value of the work minus HG Coconut’s offset for the remaining work.

 

B. Lien Foreclosure and Fraudulent Lien

 

The contractor argued that it was not paid for work performed under its off-site contract (the infrastructure work outside of developer’s land that was also needed to develop HG Coconut’s Development Area 2). HG Coconut asserted an affirmative claim against the contractor arguing that the contractor recorded a fraudulent lien.

 

The Middle District entered judgment against the contractor on its lien foreclosure claim. The fraudulent lien claim asserted by HG Coconut establishes the problems under Florida’s Lien Law with the contractor recording a lien that included Development Area 2.

 

Contractor’s performing subdivision improvements are entitled to certain protections under Florida’s Lien Law. Florida Statute s. 713.04(1) provides:

 

“Any lienor who, regardless of privity, performs services or furnishes material to real property for the purpose of making it suitable as the site for the construction of an improvement or improvements shall be entitled to a lien on the real property for any money that is owed to her or him for her or his services or materials furnished in accordance with her or his contract and the direct contract. The total amount of liens allowed under this section shall not exceed the amount of the direct contract under which the lienor furnishes labor, materials, or services. The work of making real property suitable as the site of an improvement shall include but shall not be limited to the grading, leveling, excavating, and filling of land, including the furnishing of fill soil; the grading and paving of streets, curbs, and sidewalks; the construction of ditches and other area drainage facilities; the laying of pipes and conduits for water, gas, electric, sewage, and drainage purposes; and the construction of canals and shall also include the altering, repairing, and redoing of all these things. When the services or materials are placed on land dedicated to public use and are furnished under contract with the owner of the abutting land, the cost of the services and materials, if unpaid, may be the basis for a lien upon the abutting land. When the services or materials are placed upon land under contract with the owner of the land who subsequently dedicates parts of the land to public use, the person furnishing the services or materials placed upon the dedicated land shall be entitled to a lien upon the land abutting the dedicated land for the unpaid cost of the services and materials placed upon the dedicated land, or in the case of improvements that serve or benefit real property that is divided by the improvements, to a lien upon each abutting part for the equitable part of the full amount due and owing. If the part of the cost to be borne by each parcel of the land subject to the same lien is not specified in the contract, it shall be prorated equitably among the parcels served or benefited. No lien under this section shall be acquired until a claim of lien is recorded. No notice of commencement shall be filed for liens under this section. No lienor shall be required to serve a notice to owner for liens under this section.”

 

 

However, just because a contractor performing subdivision improvements has certain lien rights, does not mean it can record a fraudulent lien. A fraudulent lien is defined in Florida Statute s. 713.31(2)(a):

 

“Any lien asserted under this part in which the lienor has willfully exaggerated the amount for which such lien is claimed or in which the lienor has willfully included a claim for work not performed upon or materials not furnished for the property upon which he or she seeks to impress such lien or in which the lienor has compiled his or her claim with such willful and gross negligence as to amount to a willful exaggeration shall be deemed a fraudulent lien.”

 

If a lien is deemed fraudulent, it is unenforceable. Fla.Stat. s. 713.31(2)(b). Additionally, an owner (or contractor, subcontractor, etc. that suffers damage from a fraudulent lien) can assert a claim for damages against the lienor for recording the fraudulent lien:

 

“An owner against whose interest in real property a fraudulent lien is filed, or any contractor, subcontractor, or sub-subcontractor who suffers damages as a result of the filing of the fraudulent lien, shall have a right of action for damages occasioned thereby. The action may be instituted independently of any other action, or in connection with a summons to show cause under s. 713.21, or as a counterclaim or cross-claim to any action to enforce or to determine the validity of the lien. The prevailing party in an action under this paragraph may recover reasonable attorney’s fees and costs. If the lienor who files a fraudulent lien is not the prevailing party, the lienor shall be liable to the owner or the defrauded party who prevails in an action under this subsection in damages, which shall include court costs, clerk’s fees, a reasonable attorney’s fee and costs for services in securing the discharge of the lien, the amount of any premium for a bond given to obtain the discharge of the lien, interest on any money deposited for the purpose of discharging the lien, and punitive damages in an amount not exceeding the difference between the amount claimed by the lienor to be due or to become due and the amount actually due or to become due.”

Fla.Stat. 713.31(2)(c).

 

 

A lien will be fraudulent if it contains willfully exaggerated amounts which can include liening for amounts that are NOT properly lienable. See Coconut 41, supra, at *15. This is why it is imperative to consult an attorney before recording a claim of lien! Not spending the due diligence in advising an attorney of the facts and the accounting comprising the amount you want to lien for can result in a fraudulent lien. Also, because a fraudulent lien contains a willful exaggeration of amounts, the lienor’s consultation with its lawyer is a factor a court can consider to determine that there was no willful exaggeration. Id. “[A] lienor can rely on consultation with counsel prior to filing the claim of lien as evidence of good faith only in the event of a full and complete disclosure of the pertinent facts to the attorney from whom the advice is sought before the lienor acts on the advice. Consultation with an attorney is not entitled to any legal weight if the contractor did not disclose all pertinent facts to the attorney.” Id. quoting Sharrard v. Ligon, 892 So.2d 1092, 1097 (Fla. 2d DCA 2004). Notably, this means that if a lienor is using this defense to counteract a fraudulent lien claim /defense, certain discussions with counsel must be waived to establish the consultation and advice to show the lien and amount was recorded and compiled in good faith.

 

Here, the contractor recorded a single claim of lien that included Development Area 2. However, the entire lien amount did NOT pertain to infrastructure improving Development Area 2.

 

The Middle District pointed out that a single claim of lien was not proper because the property liened was owned by different owners. Florida Statute s. 713.09 discusses the concept of a single claim of lien:

 

“A lienor is required to record only one claim of lien covering his or her entire demand against the real property when the amount demanded is for labor or services or material furnished for more than one improvement under the same direct contract. The single claim of lien is sufficient even though the improvement is for one or more improvements located on separate lots, parcels, or tracts of land. If materials to be used on one or more improvements on separate lots, parcels, or tracts of land under one direct contract are delivered by a lienor to a place designated by the person with whom the materialman contracted, other than the site of the improvement, the delivery to the place designated is prima facie evidence of delivery to the site of the improvement and incorporation in the improvement. The single claim of lien may be limited to a part of multiple lots, parcels, or tracts of land and their improvements or may cover all of the lots, parcels, or tracts of land and improvements. In each claim of lien under this section, the owner under the direct contract must be the same person for all lots, parcels, or tracts of land against which a single claim of lien is recorded.”

 

For this reason, the Middle District found that the lien was willfully exaggerated. In other words, the contractor acknowledged that of its approximate $195,000 lien, the pro-rata share for work done on Development Area 2 was only approximately $61,000; thus, there was an exaggeration of over $100,000 in the lien that covered Development Area 2. “The Claim of Lien was for the total amount owing for offsite work even though Westwind Contracting knew that only a substantially lesser amount was apportionable to HG Coconut.” Coconut 41, supra, at *16. Although the contractor tried to counteract the fraudulent lien by testifying that it provided its counsel with certain information, there was no testimony that it advised counsel that the lien it wanted recorded included land owned by someone other than the entity that hired it.

 

Now, even though the lien was deemed unenforceable, HG Coconut still needed to prove its damages due to the fraudulent lien. The Middle District, however, found that HG Coconut failed to prove such damages. Remember, the damages are included in Section 713.21: “court costs, clerk’s fees, a reasonable attorney’s fee and costs for services in securing the discharge of the lien, the amount of any premium for a bond given to obtain the discharge of the lien, interest on any money deposited for the purpose of discharging the lien, and punitive damages in an amount not exceeding the difference between the amount claimed by the lienor to be due or to become due and the amount actually due or to become due.” HG Coconut did NOT put any evidence of the court costs, reasonable attorneys’ fees, bond premium, or punitive damages.

 

C. Slander of Title

 

In addition to asserting an affirmative claim for fraudulent lien, HG Coconut also asserted a claim against the contractor for slander of title based on the lien. This is a common claim when a party believes a lien was improperly recorded against their property. The elements of slander of title in Florida are: 1) a falsehood, 2) that has been published or communicated to a third party, 3) the defendant knew or should have known the falsehood would result in inducing others not to deal with the plaintiff, 4) the falsehood does result in others not dealing with the plaintiff, and 5) actual and/or special damages (inclusive of attorneys’ fees) are proximately caused by the falsehood. Coconut 41, supra, at *17 quoting McAllister v. Breakers Seville Ass’n, Inc., 981 So.2d 566, 574 (Fla. 4th DCA 2008). However, even if all of the elements above are proven, a defense to slander of title is good faith. Coconut 41, supra, at *18. This defense is important because good faith raises a privilege and shifts the burden to the plaintiff asserting the claim to prove actual malice in order to recover under a slander of title theory of liability. Id. quoting McAllister v. Breakers Seville Ass’n, Inc., 981 So.2d 566, 574 (Fla. 4th DCA 2008).

 

Here, the court did not need to delve into whether there was actual malice because HG Coconut did not prove the elements of slander of title. In particular, there was no evidence that the lien caused or induced anyone not to deal with HG Coconut or that the contractor should have known the lien would have that effect. Further, there was no evidence that HG Coconut incurred any actual and/or special damages caused by the lien. While HG Coconut clearly incurred attorneys’ fees, it did not put on any evidence as to the amount of fees it incurred.

 

III.  Important Take-Aways

 

Below are important points to take-away from this case:

 

  • Unjust enrichment is a claim that can be asserted if a contractor is not in contractual privity with the owner of the land and work was knowingly performed that conferred a benefit to the owner’s land
  • An owner can offset damages in an unjust enrichment claim by asserting as a defense that the work was incomplete/ the contractor failed to fully perform its work
  • A notice to owner is not required for subdivision improvements
  •  If a lien for subdivision improvements includes multiple parcels of land, it shall be prorated among the parcels (if not otherwise stated in the contract)
  • A single claim of lien can cover different land/ parcels if the owner is the same person
  • If there are multiple contracts, there should be separate liens for each contract (even if with the same owner)
  • A fraudulent lien includes a willful exaggeration and can include amounts not properly lienable
  • A party asserting a fraudulent lien needs to present evidence of its damages: attorneys’ fees, court costs, bond transfer costs, punitive damages, etc. to be entitled to damages due to the fraudulent lien
  • Consultation will a lawyer is a defense to a fraudulent lien but all of the important communications with the lawyer regarding the formation and compilation of the lien must be waived and must come into evidence to establish the good faith basis of the lien and lien amount
  • Slander of title is a difficult claim to prove based on a construction lien; the plaintiff must show defendant knew the lien would result in third parties not dealing with the plaintiff and, in fact, third parties did not deal with plaintiff because of the lien
  • A plaintiff in a slander of title action must prove its actual and/or special damages and special damages can include attorneys’ fees
  • A defendant in a slander of title action should assert good faith as a defense which would shift the burden to the plaintiff to prove actual malice

 

For more information on fraudulent liens and slander of title, please see: https://floridaconstru.wpengine.com/owners-defending-a-lien-especially-a-patently-fraudulent-lien/

 

For more information on liens and lienable items/ amounts, please see: https://floridaconstru.wpengine.com/the-final-furnishing-date-and-lienable-amounts-for-construction-liens-decided-on-a-case-by-case-basis/

 

For more information on unjust enrichment theories, please see: https://floridaconstru.wpengine.com/subcontractors-and-unjust-enrichment-claims/

and

https://floridaconstru.wpengine.com/the-reality-when-the-construction-lender-forecloses/

 

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

CONSULTANT’S CORNER: PERSPECTIVES FROM A PROPERTY MANAGER REGARDING DEVELOPER TURNOVER

Posted on by

277559bConsultant’s Corner: In addition to providing perspectives and analysis from a lawyer, it is beneficial to hear from industry professionals and consultants. These are the folks that serve as expert witnesses during litigation / trial and consult with owners and contractors preconstruction, during construction, and postconstruction. Consultant’s Corner is dedicated towards hearing from those experienced and respected professionals.

 

 

K. Patrick Whalen (photo) is President and owner of MPlus Property Services LLC, a Community Association and Commercial Property Management Company with offices throughout Florida. Mr. Whalen is a Florida Licensed Community Association Manager and Licensed Real Estate Salesperson who has served as both an expert witness and consultant to developers and community associations from the early planning stages through turnover. Turnover of the association from the developer to the owners is a crucial milestone to associations. Having an experienced property manager that can navigate owners through the process in ensuring the developer provides all applicable funds and documentation (e.g., minutes of the association, financial records, plans and specifications, certificates of occupancy, written warranties, a turnover inspection report, etc. – see Fla.Stat. s. 718.301(4) relating to condominium association) is imperative. Mr. Whalen takes the time to provide his perspective on developer turnover as a property manager.

 

 

PERSPECTIVES ON TURNOVER

 

 

As a property manager one of the biggest challenges in maintaining a community after developer turnover is identifying sources for materials and supplies provided, such as mailboxes, light fixtures, decorative tiles and other architectural features on or in a commercial building, home or condominium, or common area.

 

images-1
Having managed and transitioned over 200 developer communities since 1989, experience has helped me to learn and understand the importance of keeping meticulous records on personnel and subcontractors working in a particular community or commercial project. While doing so may involve a considerable amount of time, it can also save you or your clients time and money months and years from now when you can go back to those notes and recall important information.

 


Over the past 25 years of managing community associations, there have been countless examples of the importance of such records, but one example illustrates how the smallest detail can save tens of thousands of dollars: In 2011, I got a call from a developer asking about a homeowners association we managed for them from beginning through turnover. The developer was concerned because they had received a letter from an attorney threatening to sue over rusting mailboxes installed at each home.
Given that the community built-out to over 5,000 homes and estimates to replace the mailboxes were about $30.00 per mailbox, with another $10.00 per mailbox to remove the old one and install the new ones, the tab for this was going to be around $200,000.00.
Sure the developer could think of a number of reasons why they should not or would not have to pay for the mailboxes, they understood that taking such a position would not be popular with their 5,000+ customers.
Just days before committing the funds, the developer recalled a detailed warranty book that we maintained and provided to the association at turnover. They took note of the fact that the book included not just the warranties on common components like the pool pump, paint and roofing for the common area amenities, but also details about decorative fixtures and finishes, like lights, maybe, just maybe, it included something about the mailboxes, even though they were not the maintenance obligation of the Association. It seemed a longshot.
At the time of their call, it had been over 5 years since turnover and the community transitioned to self-management shortly after. The warranty book given to the on-site manager was nowhere to be found. Wanting to help, we turned to our electronic back-ups for any records kept on our server regarding this community. Among the records we found was a spreadsheet on suppliers / manufacturers and details about their own individual warranties and, to our surprise, we even had scanned copies of warranty papers, which included what came inside the mailboxes—a manufactures lifetime warranty.

 

 

Without a doubt, the developer would have paid the cost to replace the mailboxes, but instead was able to make a claim with the manufacturer who not only agreed to replace the mailboxes, but also split the cost of the installation, with the other half paid by the developer. This saved our client over $180,000 in parts and labor and again reminded them of what an invaluable service partner we are to them.

 

 

 

For more information on K. Patrick Whalen:

Website: http://mplusmore.com/mplus/home.asp

Phone:  1-855-99-MPlus (67587)

Email: Patrick.Whalen@MPlusMore.com

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

CONSULTANT’S CORNER: FIVE TIPS FOR BETTER CONSTRUCTION PROJECT DOCUMENTATION

Posted on by

don carlowConsultant’s Corner: In addition to providing perspectives and analysis from a lawyer, it is beneficial to hear from industry professionals and consultants. These are the folks that serve as expert witnesses during litigation / trial and consult with owners and contractors preconstruction and during construction. Consultant’s Corner is dedicated towards hearing from those experienced and respected professionals.

 

Don Carlow (photo) is the owner of Florida Construction and Scheduling Consultants, LLC and has over twenty-five years of experience in CPM planning and scheduling, cost engineering, construction claims analysis, and program and construction management. He serves as both an expert witness and as a consultant preconstruction and during construction in scheduling, forensic delay analysis, cost and damages analysis, and litigation support on construction projects ranging in size and scope.  His project experience includes heavy civil; transportation; pipelines/underground utilities; government/military; mixed-use commercial; airports; hospitals; high-rise; theme parks; hospitality; schools/ universities; and single/multi-family residential.   Mr. Carlow has taken the time to share with us a very important article on maintaining organized and good project documentation based on his experience.

 

FIVE TIPS FOR BETTER CONSTRUCTION PROJECT DOCUMENTATION

 

cpm100-wideWhen it comes to claims and disputes, I have often heard the proverbial advice that “you should document everything.” However, in reality this is rarely done and it is often impossible to accomplish. Normally, the folks on a construction project simply don’t have the time to write down everything that’s going on at the site and at every project meeting and then respond to every email and phone call. In fact, I would not advise you to try! Doing so would be frustrating at best and counterproductive at worst. Your management team should be focused on managing the project. This is especially true on a troubled project, where you have to put out one fire after another. Your team’s efforts should be focused on using their time in the office wisely and making sure that the important items are documented. So, how are they supposed to know which of the items are the most important to document? This article attempts to answer that question by establishing some rules and by providing an objective framework that can be used when deciding how and what to document.

 

1. SUPPORT YOUR POSITION

 

For each contractual disagreement or issue, spend the time to write the letters or emails that support your position and explain why your position is correct. This should be the overall framework from which you are focusing your documentation efforts. Document the issues and events as they occur; take a photo, write an email, or put an extra note in the daily report that explains the event or occurrence from your perspective. Make sure there is evidence in the file that supports and explains your position. You’d be surprised how the resolution of an issue was changed by a single photo or a couple of sentences included in a daily report.

 

2. RESPOND TO EVERY LETTER

 

When is it necessary to write a letter? When someone writes one to you. It is not necessary to engage in a letter-writing campaign (it is simply not true that the person with the highest stack of letters automatically “wins”). But, for each letter that’s written to you make sure there is a written response in the file. One solid letter for each issue is a good rule of thumb. Get your points documented, keeping in mind tip #1, above.

 

3. BE PROFESSIONAL

 

In your written correspondence, always be professional and stick to the facts. Be objective, rational and unemotional. There is no need to tell the owner’s rep that he’s an idiot (even if he is). Many people may be involved in the resolution of the dispute after the project is over and they may never meet you. People are going to form their opinions of you based on what you say and how you say it.

 

4. GIVE NOTICE

 

Notice provisions are written into contracts for a reason. Their purpose is to give the other party time to investigate, mitigate expenses, and track costs. Read your contract and make sure you are complying with the notice requirements. To make giving notice easier, we recommend that our clients develop form notices. At a minimum, we suggest having form notices available for each of the following situations: (a) Excusable Delay/Request for Time Extension, (b) Differing Site Condition, (c) Conflicting Specifications, (d) Acceleration (Directed or Constructive), (e) Disruption of Work Force, and (f) A/E Change. Have your lawyer review the notices before using them in the field.

 

5. RESERVE YOUR RIGHTS

 

I have been involved in several lawsuits in which the judge upheld signed releases on payment applications and change orders, and barred recovery for damages. Have your lawyer review the release language on any document before you sign it. At a minimum, cross out the offending language, or simply write that you are reserving your right to additional money or time for the impact encountered on the project or as a result of the change.

 

Knowing how and what to document will keep your team focused on managing the project and put your company in a much better position when it comes to resolving disputes when they arise.
Please contact Don Carlow for more information regarding the value he can provide to your construction project or litigation team. He can be reached at the following contact information:
Website: http://florida-consultants.com/
Email: don@florida-consultants.com
Phone: (407) 603-6165

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

CONDOMINIUM ASSOCIATION RIGHTS REGARDING CONSTRUCTION DEFECTS & THE STATUTE OF LIMITATIONS FOR STATUTORY IMPLIED WARRANTIES

Posted on by

imagesContractors, subcontractors, suppliers, developers, and design professionals that are involved in the design and construction of condominiums need to appreciate three items relating to the construction of condominiums and the rights of condominium associations:

 

(1) The condominium association, upon turnover from the developer to the unit owners, may sue for matters affecting the common elements or matters of common interest concerning most or all of the unit owners (Fla. Stat. s. 718.111)

 

(2) The condominium association’s statute of limitations to assert construction defect claims does not begin to accrue until the developer has turned over control of the association to the unit owners (Fla. Stat. s. 718.124); and

 

(3) The developer, the contractor, subcontractors, and suppliers owe certain statutory implied warranties to the unit owners that can be asserted by the association as a class representative (Fla. Stat. s. 718.203). For instance, under Fla. Stat. 718.203(2): “The contractor, and all subcontractors and suppliers, grant to the developer and to the purchaser of each unit implied warranties of fitness as to the work performed or materials supplied by them as follows: (a) For a period of 3 years from the date of completion of construction of a building or improvement, a warranty as to the roof and structural components of the building or improvement and mechanical and plumbing elements serving a building or an improvement, except mechanical elements serving only one unit.”

 

A.  THE STATUTE OF LIMITATIONS FOR STATUTORY IMPLIED WARRANTY CLAIMS

 

A topic that comes up is the statute of limitations for an association to assert a statutory implied warranty claim since the statutory implied warranties kick in from the completion of the building (i.e., the Certificate of Occupancy) and are of a shorter time period than the four year statute of limitations period from the time the defect was discovered (or should have been discovered with the exercise of due diligence).

 

This issue was addressed by the Florida Supreme Court in Charley Tropino & Sons, Inc. v. Seawatch at Marathon Condominium, Ass’n, Inc., 658 So.2d 922 (Fla.1994). In this case, three condominium buildings were constructed and the last building received its Certificate of Occupancy in April 1983. The association was turned over from the developer to the unit owners more than two years later in August 1985. The association then asserted a construction defect lawsuit that included claims for breach of statutory warranties against the general contractor, developer, etc., (over defective concrete and metal decking) in May 1988: more than five years from the Certificate of Occupancy of the last building and almost two years from when the association was turned over to the unit owners.

 

The Florida Supreme Court was asked to determine whether the turnover of the association from the developer to the unit owners extended the time for unit owners to assert a breach of statutory implied warranty claim.  (Based on the facts of the case, the question was whether the association in 1988 could assert breach of statutory warranty claims against the developer, general contractor, etc., when the Certificate of Occupancy was issued more than five years earlier for the last building and unit owners obtained control of the association approximately two years earlier.) The Court answered this question “Yes,” maintaining:

 

“[A] condominium association has a statutory right to file suit on behalf of its unit owners for breach of implied warranty of fitness and merchantability for construction defects affecting the common interest. Such a suit must be filed within the general time limits set out in chapter 95, but the commencing of this limitations period shall be tolled until control of the association passes from the developer to the unit owners.”
Charley Tropino, 658 So.2d 925.

 

This means that the statutory implied warranty period is not a statute of limitations. Rather, it is simply the time period in which the life of the warranty applies to cover defects that occur within that time period. However, these claims are then tolled until the association is turned over to the unit owners at which time the association has four years to assert its breach of statutory warranty claims. See Saltponds Condominium Ass’n v. Walbridge Aldinger Co., 979 So.2d 1240 (Fla.3d DCA 2008) (a condominium association was turned over in August 2002 and had until August 2006 to preserve its rights to sue for breach of statutory implied warranty claims).

 

Let’s apply this law to hypotheticals because it is confusing:

 

Hypothetical 1: A Certificate of Occupancy was issued for a condominium tower in March 2005. The condominium association was turned over to the unit owners on April 2008. Due to construction defects, the association filed a lawsuit against the general contractor for structural defects in February 2012 that included breach of statutory warranty claims.

 

Under s. 718.203, as referenced above, the contractor owes to the association an implied warranty for structural components from three years from the completion of the building (defined as the Certificate of Occupancy date). This means that a breach of this implied warranty should have taken place between March 2005 (Certificate of Occupancy date) and March 2008 (three years from that date). But, and this is an important but, the condominium association does not need to file suit on this breach of the implied warranty until April 2012 (four years from the April 2008 date the condominium association was turned over to the unit owners since the statute of limitations is tolled until an association is turned over to the unit owners).

 

Hypothetical 2: An interesting twist to the above hypothetical is if the association did not file its lawsuit until March 2014-nine years from the Certificate of Occupancy date and six years from the turnover date. Under these dates, the association will have to assert that it did not discover the defects until on or after March 2010 in order to fall within the four year statute of limitations. However, by doing this, the condominium association really should NOT have a breach of statutory warranty claim against the general contractor because the life of the warranty would have expired before the breach of that duty was actually discovered.

 

Hypothetical 3: Now, let’s assume the association did not file suit until March 2016 or eleven years from the Certificate of Occupancy date and argues that it did not discover the defects until March 2014. Under this context, the association should not have any claims since the turnover of the association to unit owners has no bearing and does not toll the ten year statute of repose period to file suit (i.e., the last date a lawsuit must be filed-not matter what). See Sabal Chase Homeowners Ass’n, Inc. v. Walt Disney World Co., 726 So.2d 796 (Fla. 3d DCA 1999) (finding that turnover of condominium association to unit owners did not extend the statute of repose).

 

B.  TIDBITS FOR CONTRACTORS CONSTRUCTING CONDOMINIUMS

 

General contractors constructing condominiums need to operate under the presumption that there is a strong likelihood that the association will assert construction defect related claims including breach of statutory warranty claims. Many condominium associations retain engineers at turnover or shortly thereafter to perform a comprehensive analysis of the plans, as-built plans, submittals, and condition of the condominium to determine if there are any design / construction defects. Associations will want to do this to ensure they preserve warranty-related items / claims and provide parties notice of those items sooner than later. Contractors, knowing claims are forthcoming, need to be proactive:

 

  • They will want to hire subcontractors that do not have residential or condominium exclusions in their policies, or an exclusion in a liability policy that excludes coverage for condominium projects.
  • They will want to ensure that they maintain the appropriate liability coverage with completed operations coverage and are identified as an additional insured under subcontractor policies.
  • They may want to account for the presumed claim in their price knowing that certain overhead may be devoted to addressing claims long after completion.
  • I have also seen escrow provisions included in the developer-contractor contract where an escrow account is to be funded and maintained during the statute of repose period to offset claims. I have never been a big fan of this since (i) parties prefer to have the money instead of having that money fund an account for ten years, (ii) it could, perhaps, serve as motivation that there is money to fund claims that are not otherwise insurable claims, and (iii) it could lead to disputes down the road as to the allocation of that money in the event a dispute is initiated and fingers are pointed as to the cause of the defect.
  • If the contractor and the developer are in a dispute over certain defects and a settlement is reached, the settlement should reflect that the developer is entering into this agreement on behalf of the association (assuming it is still in control of the association) and accepts money, etc., for the specific items in consideration for a full and final release for the defects. This way, at a minimum, the contractor could create an argument in the event the association later files suit against the contractor for the same exact defects that the defects were already resolved and accepted by the developer on behalf of the association.

 

For more on condominium statutory warranties, please see https://floridaconstru.wpengine.com/florida-condominium-acts-statutory-warranties-difference-between-manufacturer-and-supplier/

 

https://floridaconstru.wpengine.com/statutory-implied-warranties-for-condominium-associations/

 

For more on the statute of limitations and statute of repose, please see: https://floridaconstru.wpengine.com/watering-down-the-10-year-statute-of-repose-period-for-construction-disputes/

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

 

WATERING DOWN THE 10 YEAR STATUTE OF REPOSE PERIOD FOR CONSTRUCTION DEFECT DISPUTES

Posted on by

platYes, it appears that the Second District Court of Appeals in Clearwater Housing Authority v. Future Capital Holding Corp., 38 Fla. L. Weekly D2323a (2nd DCA 2013), just entered an opinion that has watered down the ten year statute of repose for construction disputes. That is right – watered down the statute of repose. This is excellent for owners with construction latent defect disputes, but bad for contractors and design professionals.

 

The statute of limitations for construction disputes is governed by Florida Statute s. 95.11(3)(c):

 

(c) Within Four Years. An action founded on the design, planning, or construction of an improvement to real property, with the time running from the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion or termination of the contract between the professional engineer, registered architect, or licensed contractor and his or her employer, whichever date is latest; except that, when the action involves a latent defect, the time runs from the time the defect is discovered or should have been discovered with the exercise of due diligence. In any event, the action must be commenced within 10 years after the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion or termination of the contract between the professional engineer, registered architect, or licensed contractor and his or her employer, whichever date is latest.

 

The bolded language above is the ten year statute of repose language, which means that a lawsuit brought after this date is forever barred even if it is otherwise filed within four years from the date an owner discovered a latent defect (the statute of limitations period). In other words, after this repose period, latent defects become moot.

 

However, the Second District in Clearwater Housing Authority gave owner an excellent argument to extend the repose period. In this case, an owner hired a contractor and design professionals for purposes of building an apartment project in Clearwater. The property was then purchased by Clearwater Housing Authority. The Certificate of Occupancy was issued in 2000 and this was when Clearwater Housing Authority took possession of the property. However, a final plat was not submitted by the engineers on the project until 2003.

 

In 2009, Clearwater Housing Authority initiated a dispute for construction defects against various parties. But, in 2011, it amended its complaint to assert a claim against Future Capital Holding Corporation (“Future Capital”). Future Capital did the right thing and moved for summary judgment due to the expiration of the statute of repose. The math was simple. The Certificate of Occupancy occurred in 2000 and it was brought into the lawsuit in 2011, more than 10 years after-the-fact. The trial court agreed and summary judgment was entered in favor of Future Capital.

 

Clearwater Housing Authority creatively argued that the engineer did not submit the final plat until 2003 and this marked the date that triggered the beginning of the repose period; thus, it had until 2013 to assert claims for construction defects. This argument was based on the repose language: “[T]he action must be commenced within 10 years after the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion or termination of the contract between the professional engineer, registered architect, or licensed contractor and his or her employer, whichever date is latest.” Stated differently, “the [ten year] repose period commences on the latest date that any of the listed entities—the professional engineer, registered architect, or licensed contractor—completed or terminated their contract.” Clearwater Housing Authority, supra.

 

The Second District reversed the summary judgment based on Clearwater Housing Authority’s argument and because an issue of fact remained as to when the contract was completed.

 

What effect does this have? A huge effect! An owner can sue a contractor or design professional outside of ten years from the issuance of the Certificate of Occupancy and argue that the repose period did not run based on the following arguments: (a) the contractor’s contract was not completed until well after the Certificate of Occupancy date because the contractor was doing endless punchlist work or (b) the design professional had not completed its contract because it was required to submit as-built plans (or some relatively minor task) which it did not do until well after the Certificate of Occupancy. Therefore, based on this holding, owners can be very creative as to when contracts were arguably completed to create questions of fact to postpone the repose period, especially if they are concerned with this defense. On the other hand, contractors and design professionals sued for construction defects that otherwise have a statute of repose argument, like Future Capital seemed to have in the Clearwater Housing Authority case, need to appreciate that a creative owner will be able to create a question of fact to preclude the entry of summary judgment.

 

 

 

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.